Board of Contract Appeals
                 General Services Administration
                      Washington, D.C. 20405



                                             
                 ________________________________

                     GRANTED:  April 7, 2004
                 ________________________________


                GSBCA 16127-TD, 16358-C(16127-TD)


                CORNING CONSTRUCTION CORPORATION,

                                                  Appellant,

                                v.

                   DEPARTMENT OF THE TREASURY,
                                 
                                                  Respondent.

     Joseph H. Kasimer of Kasimer & Annino, P.C., Falls Church, VA, counsel for
Appellant.

     Marvin Kent Gibbs and Diane Mullaney, Office of Chief Counsel, Bureau of
Engraving and Printing, Department of the Treasury, Washington, DC, counsel for
Respondent.

Before Board Judges DANIELS (Chairman), BORWICK, and HYATT.

HYATT, Board Judge

     On behalf of its subcontractor, Prospect Waterproofing Company, appellant, Corning
Construction Corporation, appealed a decision issued by a contracting officer of the Bureau
of Engraving and Printing (BEP), Department of the Treasury (respondent), denying a claim
for an equitable adjustment for the cost of extra work and an extension of time in connection
with a contract to replace the roof on respondent's main building in Washington, D.C. 
Corning elected to have its appeal processed in accordance with the accelerated procedure
provided in Board Rule 203 (48 CFR 6102.3 (2003)).  On October 29, 2003, the Board
granted the appeal as to entitlement.  Corning Construction Corp. v. Department of the
Treasury, GSBCA 16127-TD, 03-2 BCA   32,402, reconsideration denied (Jan. 15, 2004). 

     On April 2, 2004, the parties requested that the Board issue a decision adopting their
joint stipulation settling the quantum portion of the appeal for the amount of $84,108.82  and
extending the time for completion of the contract by nineteen days.  The parties' stipulation
also provides for interest on the award, computed in accordance with the terms of the
Contract Disputes Act of 1978, 41 U.S.C.   611 (2000), in the total amount of $9752.52, and
for an award of attorney fees to Corning in the amount of $11,322.50.  The award of attorney
fees resolves Corning's pending application, docketed as GSBCA 16358-C(16127-TD), for
Equal Access to Justice Act (EAJA) attorney fees and costs attributable to the underlying
appeal.  In all, the parties agree that the total amount of $105,183.84 shall be paid to Corning.

     The parties have also agreed that they will not seek reconsideration of, or relief from,
the Board's decision and that they will not appeal the decision. 

                             Decision

     The matters docketed as GSBCA 16127-TD and GSBCA 16358-C(16127-TD) are
GRANTED in accordance with the joint stipulation of the parties.  Rule 136(e).  The
combined award, in the amount of $105,183.84, is to be paid from the permanent indefinite
judgment fund.  31 U.S.C.   1304 (2000).



                                   __________________________________
                                   CATHERINE B. HYATT
                                   Board Judge

We concur:



____________________________________    __________________________________
STEPHEN M. DANIELS                 ANTHONY S. BORWICK
Board Judge                             Board Judge