Board of Contract Appeals General Services Administration Washington, D.C. 20405 ________________________________ GRANTED: April 2, 1999 ________________________________ GSBCA 13880, 13881, 13950, 13951, 13952, 13953, 13954, 13955, 13956, 13957, 13958, 13959, 14115, 14136, 14687, 14688, 14689, 14690, 14691, 14692, 14693, 14694, 14695, 14696, 14697, 14698, 14699, 14700, 14701, 14702 BPT COURTHOUSE ASSOCIATES, Appellant, v. GENERAL SERVICES ADMINISTRATION, Respondent. Richard L. Abramson and Patrick J. Greene, Jr., Peckar & Abramson, River Edge, NJ, counsel for Appellant. Gerald L. Schrader, Office of General Counsel, General Services Administration, Washington, DC, counsel for Respondent. Before BORWICK, HYATT, and GOODMAN, Board Judges. HYATT, Board Judge. These appeals arise out of contract number GS-05P-93-GBC-0004, for the design and construction of a new Federal Building and United States Courthouse in Minneapolis, Minnesota. This contract, between BPT Courthouse Associates, appellant, and the General Services Administration (GSA), respondent, generated various claims for equitable adjustments for additional costs incurred by the contractor and its general contractor, Turner Construction, as a result of alleged extra work, delay, and acceleration. The parties have negotiated a settlement of these appeals and, on April 1, 1999, filed a joint stipulation of judgment with the Board, stipulating to the entry of judgment as follows: The GSA agrees to pay to BPT (and through it, Turner) no later than April 5, 1999, and BPT and Turner agree to accept, the sum of $9,950,000.00 in full satisfaction of all claims of BPT and its subcontractors, including but not limited to Turner, arising out of the Project. The above amount is inclusive of all interest, fees, expenses and other related costs. GSA's payment to BPT (and through it, Turner) of the entire sum of $9,950,000.00 will be made by April 5, 1999 ("Due Date"). In the event GSA does not make payment by the Due Date, all monies owed shall bear interest at the Contract Disputes rate from the Due Date until paid. BPT and GSA further stipulate that they will promptly execute certificates of finality on the basis of this stipulated judgment. Decision This appeal is GRANTED in accordance with the parties' stipulated settlement. Rule 136(e)(48 CFR 6101.36(e)(1998)). This award is to be paid from the permanent indefinite judgment fund, 31 U.S.C. 1304 (Supp. III 1997). ____________________________ CATHERINE B. HYATT Board Judge We concur: _________________________________ ________________________________ ANTHONY S. BORWICK ALLAN H. GOODMAN Board Judge Board Judge